Transcription of Engineering Procurement and Construction (EPC)
{{id}} {{{paragraph}}}
Example: stock market
Engineering Procurement and Construction (EPC)
Engineering Procurement and Construction (EPC) Agreement For [Name of the Road/Bridge Work] Ministry of Road Transport & Highways (MoRT&H) March 2019 i Table of Contents Part I 1 Preliminary 1 1 Definitions and Interpretations 5 Definitions 5 Interpretation 13 Measurements and arithmetic conventions 15 Priority of agreements and errors/discrepancies 15 Joint and several liability 16 Part II 18 Scope of Project 18 2 Scope of the Project 21 Scope of the Project 21 3 Obligations of the Authority 22 Obligations of the Authority 22 Maintenance obligations prior to the Appointed Date 24 Environmental Clearances 24 Deemed Termination upon delay 24 4 Obligations of the Contractor 25 Obligations of the Contractor 25 Obligations relating to sub-contracts and any other agreements 27 Employment of foreign nationals 28 Contractor s personnel 28 Advertisement on Project Highway 29 Contractor's care of the Works 29 Electricity.
25.3 Notice and contest of claims 129 25.4 Defence of claims 129 25.5 Survival on Termination 130 26 Dispute Resolution 131 26.1 Dispute Resolution 131 26.2 Conciliation 131 26.3 Arbitration 131 26.4 Adjudication by Regulatory Authority, Tribunal or Commission 132 27 Miscellaneous 133 27.1 Governing law and jurisdiction 133
Tags:
Information
Domain:
Source:
Link to this page:
Please notify us if you found a problem with this document: