Construction Disputes in India - Nishith Desai

1 M U M BA I S I L I C O N VA L L E Y BA N G A LO RE S I N G A P O RE M U M BA I B KC NEW DELHI MUNICH N E W YO RK. Construction Disputes in India April 2020. Copyright 2020 Nishith Desai Associates Construction Disputes in India April 2020. DMS Code: RSRCH 9000-5039. Nishith Desai Associates 2020. Construction Disputes in India About NDA. We are an India Centric Global law firm ( ) with four offices in India and the only law firm with license to practice Indian law from our Munich, Singapore, Palo Alto and New York offices. We are a firm of specialists and the go-to firm for companies that want to conduct business in India , navigate its complex business regulations and grow. Over 70% of our clients are foreign multinationals and over are repeat clients. Our reputation is well regarded for handling complex high value transactions and cross border litigation; that prestige extends to engaging and mentoring the start-up community that we passionately support and encourage. We also enjoy global recognition for our research with an ability to anticipate and address challenges from a strategic, legal and tax perspective in an integrated way.

2 In fact, the framework and standards for the Asset Management industry within India was pioneered by us in the early 1990s, and we continue to remain respected industry experts. We are a research based law firm and have just set up a first-of-its kind IOT-driven Blue Sky Thinking & Research Campus named Imaginarium AliGunjan (near Mumbai, India ), dedicated to exploring the future of law & society. We are consistently ranked at the top as Asia's most innovative law practice by Financial Times. NDA is renowned for its advanced predictive legal practice and constantly conducts original research into emerging areas of the law such as Blockchain, Artificial Intelligence, Designer Babies, Flying Cars, Autonomous vehicles, IOT, AI & Robotics, Medical Devices, Genetic Engineering amongst others and enjoy high credibility in respect of our independent research and assist number of ministries in their policy and regulatory work. The safety and security of our client's information and confidentiality is of paramount importance to us.

3 To this end, we are hugely invested in the latest security systems and technology of military grade. We are a socially conscious law firm and do extensive pro-bono and public policy work. We have significant diversity with female employees in the range of about 49% and many in leadership positions. Nishith Desai Associates 2020. Provided upon request only Accolades A brief chronicle of our firm's global acclaim for its achievements and prowess through the years . Legal500: Tier 1 for Tax, Investment Funds, Labour & Employment, TMT and Corporate M&A. 2020, 2019, 2018, 2017, 2016, 2015, 2014, 2013, 2012. Chambers and Partners Asia Pacific: Band 1 for Employment, Lifesciences, Tax and TMT. 2020, 2019, 2018, 2017, 2016, 2015. IFLR1000: Tier 1 for Private Equity and Project Development: Telecommunications Networks. 2020, 2019, 2018, 2017, 2014. AsiaLaw Asia-Pacific Guide 2020: Tier 1 (Outstanding) for TMT, Labour & Employment, Private Equity, Regulatory and Tax FT Innovative Lawyers Asia Pacific 2019 Awards: NDA ranked 2nd in the Most Innovative Law Firm category (Asia-Pacific Headquartered).

4 RSG-Financial Times: India 's Most Innovative Law Firm 2019, 2017, 2016, 2015, 2014. Benchmark Litigation Asia-Pacific: Tier 1 for Government & Regulatory and Tax 2019, 2018. Who's Who legal 2019: Nishith Desai , Corporate Tax and Private Funds Thought Leader Vikram Shroff, HR and Employment Law- Global Thought Leader Vaibhav Parikh, Data Practices - Thought Leader ( India ). Dr. Milind Antani, Pharma & Healthcare only Indian Lawyer to be recognized for Life sciences-Regulatory,' for 5 years consecutively Merger Market 2018: Fastest growing M&A Law Firm in India Asia Mena Counsel's In-House Community Firms Survey 2018: The only Indian Firm recognized for Life Sciences IDEX legal Awards 2015: Nishith Desai Associates won the M&A Deal of the year , Best Dispute Management lawyer , Best Use of Innovation and Technology in a law firm and Best Dispute Management Firm . Nishith Desai Associates 2020. Construction Disputes in India Please see the last page of this paper for the most recent research papers by our experts.

5 Disclaimer This report is a copy right of Nishith Desai Associates. No reader should act on the basis of any statement contained herein without seeking professional advice. The authors and the firm expressly disclaim all and any liability to any person who has read this report, or otherwise, in respect of anything, and of consequences of anything done, or omitted to be done by any such person in reliance upon the contents of this report. Contact For any help or assistance please email us on or visit us at Acknowledgements Vyapak Desai . Ashish Kabra Kshama Loya Modani Mohammad kamran Nishith Desai Associates 2020. Construction Disputes in India Contents EXECUTIVE SUMMARY 01. Construction ARBITRATION IS A SPECIALISED. AREA OF EXPERTISE 02. 1. Construction CONTRACTS 03. I. Formation of Construction Contracts 03. II. Typical Documentation in Construction Contracts 04. III. Forms of Construction Contracts 05. IV. Standard Forms of Construction Contracts 09. V. Pricing Methodologies 10.

6 3. Disputes ARISING OUT OF Construction CONTRACTS 12. 4. DELAYS IN Construction PROJECTS 13. I. Critical Path and Float 14. II. Types of Delay Analysis Methodology 14. III. Interplay between the Indian Contract Act and Delay 15. 5. EXTENSION OF TIME (EOT) IN Construction CONTRACTS 17. 6. VARIATION IN Construction CONTRACTS 18. I. Formal requirements of variation 19. II. Example of a valuation clause 19. 7. NOTIFICATION FOR EOT CLAIMS 21. 8. REMEDIES FOR BREACH 23. I. Damages 23. II. Speci c Relief 26. 9. DISPUTE RESOLUTION MECHANISMS 28. I. Multi-Tier Dispute Resolution Clauses (MTDRC) 28. II. Dispute Adjudication Board (DAB) 29. 10. Construction Disputes : PRACTICE STATEMENT 32. Nishith Desai Associates 2020. Construction Disputes in India Executive Summary The Construction industry is expected to be Construction activities. This paper provides a one of the highest drivers of economic growth brief overview of Construction contracts, types worldwide. It encapsulates a range of activities of contracts, price models, and issues arising involving complex infrastructure projects, out of Construction contracts.

7 It further deals engineering works, commercial and residential with rights of parties and reliefs available to Construction , built up works, development the parties, along-with dispute resolution projects, among others. mechanisms when faced with Construction Disputes . The key focus of this paper lies in The Construction industry has important arbitration as an effective mode of alternate linkages with other sectors, so that its impact dispute resolution, and the need for effective on GDP and economic development goes well case management techniques in arbitration to beyond the direct contribution of Construction bring about effective and timely resolution of Construction Disputes . In India , Construction (infrastructure) is among At Nishith Desai Associates, the Infrastructure the top ten largest sectors attracting highest Dispute Resolution team has expertise in foreign direct investment (FDI). FDI inflows in drafting and interpretation of key provisions the Construction sector including infrastructure in Construction contracts, and advice on activities has risen manifold in the last two years implications of provisions in existing from USD 1861 million to USD 2258 Construction contracts.

8 We work with multiple In the 2018-2019 budget, the government technical experts and civil engineers, often with increased its expenditure towards infrastructure project management consultants, to ensure development by - from USD billion seamlessness and uniformity of documents in the Financial Year (FY) 2017-2018 to USD involved in all stages of drafting of Construction billion in FY2018-2019. contracts. This helps our clients by preventing In the Global Construction 2030 report, contradictions or inconsistencies between early PriceWaterCoopers forecasts that by 2030, the stage documents such as specifications etc. and worldwide volume of Construction output will subsequent stage documents such as conditions grow by 85% to USD trillion, with three of contract; helps maintain compatibility countries, China, US and India , leading the way between early stage and subsequent stage and accounting for 57% of all global growth. contractual provisions; and work out tenable programme schedules and procedures that align It is thus clear that Construction is proving to with the requirements spelt out at the initial be one of the most dynamic sectors not only stage.

9 In addition, we advise on pre-litigation on a global scale, but also in India . With a strategy, and conduct complex Construction sector subject to extreme technicalities and dispute arbitration including projects complexities, it is only rational to infer that involving parties from multiple jurisdictions Disputes arising out of Construction activities in international commercial and bilateral would also call for distinct expertise and in investment treaty arbitration. depth understanding of the issues surrounding 1. last available on August 10, 2019. 2. Nishith Desai Associates 2020 1. Provided upon request only Construction Arbitration is a Specialised Area of Expertise Disputes arising out of Construction contracts are by lenders and credit providers. Insurance is distinctly different from other body of Disputes . another dominant segment. Security in the form of They are highly technical and complex in guarantees or bonds pave way to a distinct range of nature, almost always call for urgent resolution, Disputes against financial institutions.

10 And involve a multitude of parties. Issues of While Construction Disputes only arise out of joinder and consolidation gain prominence Construction contracts, an available opportunity in these Disputes like no other dispute forms. to reduce instances of dispute and mitigate Construction contracts involve several risks, and impact is to engage in careful study and drafting resultantly witness a greater need for effective of Construction contracts. The law of contracts allocation of risk amongst various parties. not only determines the applicable principles Ascertaining the liability of a party in a string for ascertaining liability after a dispute arises; it of parties therefore requires careful study of also helps ascertain whether a valid Construction responsibilities and obligations of each party, contract has been formed at the first stage. Pre- nature of commission or omission resulting contract documents such as tenders, letters of in breach of obligation, and calculating the intent etc.